Welcome to DDS Interiors (“we”, “our”, or “us”). By accessing our website ddsinteriors.com or engaging our interior design, consultation, and execution services, you agree to comply with and be bound by the following Terms and Conditions. Please review them carefully before booking a consultation or commencing any project with us.
1. Acceptance of Terms
By using our website, scheduling a free consultation, or entering into a service agreement with DDS Interiors, you accept these Terms and Conditions in full. If you disagree with any part of these terms, please do not use our website or services.
2. Services Offered
DDS Interiors provides professional interior design and execution services, which include but are not limited to:
- Residential Interior Design: Tailored designs for apartments, villas, and luxury houses.
- Commercial Interior Design: Layouts and execution for office buildings, retail stores, restaurants, and medical clinics.
- Modular Kitchen Design: Custom modular setups with high-end finishes and hardware.
- Customized Furniture & Layouts: Specialized storage, wardrobes, television cabinets, and space planning.
- 3D Design Visualization and turnkey project management.
3. Consultations and Quotations
- Free Consultation: Initial consultation sessions offered by DDS Interiors are subject to availability and project scope.
- Quotations: Cost estimates and project quotations provided after space planning are valid for a specified period (typically 30 days) and may be revised if project requirements, material choices, or site dimensions change.
4. Payment Terms & Execution Milestones
- Projects follow a milestone-based payment structure (e.g., advance upon design sign-off, intermediate payments during execution, and final clearance prior to handover).
- Work on-site or procurement of custom materials (such as modular kitchen components or custom furniture) begins only upon receipt of the agreed milestone payments.
- Delays in payments may result in corresponding extensions to the projected on-time delivery schedule.
5. Intellectual Property Rights
- All content on ddsinteriors.com, including text, graphics, logos, 3D design renderings, layout plans, and photographs, is the intellectual property of DDS Interiors.
- Clients may not reproduce, distribute, or use our design drawings or 3D concepts for commercial purposes or with third-party contractors without explicit written consent from DDS Interiors.
6. Client Responsibilities
- Site Access: The client must ensure unhindered access to the property/site for measurements, material delivery, and labor during agreed-upon hours.
- Approvals: The client is responsible for obtaining any necessary society, building, or municipal permissions required for renovation work in Mumbai apartments or commercial complexes.
7. Limitation of Liability
- While we strive for precise execution and on-time delivery, DDS Interiors shall not be held liable for project delays caused by force majeure events, labor strikes, material shortages beyond our control, or delays in client approvals.
- Our total liability for any claim arising out of our services shall not exceed the total design or project management fees paid by the client to DDS Interiors for that specific service.
8. Governing Law and Jurisdiction
These Terms and Conditions are governed by and construed in accordance with the laws of India. Any disputes arising in connection with these terms or our services shall be subject to the exclusive jurisdiction of the courts located in Mumbai, Maharashtra.
9. Changes to Terms
We reserve the right to modify or replace these Terms and Conditions at any time. Any changes will be posted on this page with an updated effective date. Continued use of our website or services following any changes constitutes acceptance of those changes.
10. Contact Information
If you have any questions or concerns regarding these Terms and Conditions, please contact us:
- Company Name: DDS Interiors
- Location: Mumbai, India
- Phone: +91 9136957557